Introduction
Welcome to the Switch Installation Ltd website. By accessing or using our services, you agree to comply with and be bound by the following terms and conditions. If you do not agree with these terms, please do not use our services.
1. Definitions
In these terms and conditions, “we,” “us,” and “our” refer to Switch Installation Ltd, and “you” and “your” refer to the individual or entity using our services.
2. Services
Switch Installation Ltd provides a range of storage solutions, including shelving and racking systems. We aim to deliver high-quality products and services to meet your needs.
3. Quotations and Orders
All quotations provided by us are subject to change and are valid for a limited time. Once you accept a quotation, an order will be placed, and we will confirm the details via email. All orders are subject to availability.
4. Payment
Payment terms will be outlined in the quotation. We accept various payment methods, and payment must be made in full before the delivery of goods or commencement of services unless otherwise agreed in writing.
5. Delivery
We aim to deliver your order within the specified timeframe; however, delivery dates are estimates only and not guaranteed. We are not liable for any delays beyond our control.
6. Installation
If you have requested installation services, our team will arrange a suitable time to complete the installation. You are responsible for ensuring that the installation area is clear and accessible.
7. Warranty
We provide a warranty on our products as outlined in your quotation. This warranty covers defects in materials and workmanship but does not cover misuse, wear and tear, or damage caused by external factors.
8. Liability
Switch Installation Ltd is not liable for any indirect, incidental, or consequential damages arising from the use of our products or services. Our total liability is limited to the amount paid for the goods or services in question.
9. Cancellation and Returns
You may cancel your order within a specified period after placing it, provided the products have not been dispatched. Returns will only be accepted for faulty or damaged goods within a specified timeframe, and you must notify us immediately upon receiving the goods.
10. Governing Law
These terms and conditions are governed by the laws of England and Wales. Any disputes arising from these terms shall be subject to the exclusive jurisdiction of the courts of England and Wales.
11. Changes to Terms
We reserve the right to amend these terms and conditions at any time. Any changes will be posted on our website, and your continued use of our services constitutes acceptance of those changes.
12. Contact Us
If you have any questions or concerns regarding these terms and conditions, please contact us at:
Email: sales@switchinstallation.co.uk
Phone: 0151 334 8000
Thank you for choosing Switch Installation Ltd. We look forward to serving you!